The URL can be used to link to this page

Home My WebLink AboutB14-0140 window cut sheets Proposal - Detailed � Pella Window and Door Showroom of Glenwood Springs Sales Rep Name: �> 5072 County Road#154 Sates Rep Phone: Glenwood Springs, CO 81601 Sales Rep E-Mail: Phone:9709452289 Fax: 9709454419 Sales Rep Fax: Triebel, Michael (970) 945-2289 mtriebel@pellacolorado.com (970)945-4419 Customer Information Project/Delivery Address Order Information HMR construction HMR/All Seasons G-1B Quote Name: Fiberglass Egress PO BOX 2502 232 Vail Valley Drive G1-B Order Number: 042MT0982 EDWARDS,CO 81632 Lot# Quote Number: 4684070 Primary Phone:(970)328-0581 VAIL,CO 81657 Order Type: Non-Installed Sales Mobile Phone: County: EAGLE Wall Depth: Fax Number: (970)9260250 Owner Name: Payment Terms: Net 30 Days E-Mail: HMR construction Tax Code: ZZq Contact Name: Owner Phone: (970)328-0581 Cust Delivery Date: 05114/2014 Quoted Date: 5/11/2013 Great Plains#; 8403029 Contracted Date: 4/22/2014 Customer Number: 1002826106 Booked Date: Customer Account: 1000478143 Customer PO#: Customer Notes: AW317 for discount BP-614-0054 10 6_' G PK# �:' 628 � � „ �'i _ Viewed From Exterior Rough Opening; 6'0"X 3'0" Impervia, Sliding Window Vent Right I Fixed, 71.5 X 35.5, Brown Item Price Qty ExYd Price $381.46 Z $762.92 1:7236 Vent Right/Fixed Double Slider Frame Slze:71 1/2 X 35 1/2 General Information: Standard,Duracast0,Block,Foam insulated,3", 1 5/16", 1 11/16" Exterior Color/Finish:Brown Interior Color/Finlsh:White,Two Color Glass:Insulated Low-E Advanced Low-E Insulating Glass Argon High Altitude Hardware Options:White Screen:Half Screen,Conventional Fibergtass Grille:No Grille, Wrapping Information:Standard Fin,No Exterior Trim,No Interior Trim,Pella Recommended Clearance,Perimeter Length=214",Glazing Pressure=70 For more information regarding the finishing, maintenance, service and warranty of all PellaO products, visit the PellaO website at www.pella.com Printed on 4/2212014 Detailed Proposal Page 1 of � � � � ♦ � 5 � � Customer: HMR construction Project Name: HMRIAII Seasons G-16 Quote Number:4684070 are manufactured and/or supplied. If Customer at any time fails to pay PWD for the materials supplied,PWD may,at it's option,suspend all deliveries or terminate the Contract with the Customer.Such suspension or termination DOES NOT excuse payment for those materials and products already manufactured at the full contract price or payment for any component parts already purchased and obtained by PWD. Title Title,ownership and the right to possession of the product or materials furnished or to be furnished by PWD shal�remain in PWD until PWD is paid in full. PWD shall have a right to possession of the product or materials but is not obiigated to repossess the materials in the event of non-payment.PWD's right to repossess materials is in addition to,and not a limitation upon or a waiver of PWD's other legal rights including the right to place mechanic's liens against the real property for which materials were supptied.All risk of loss or damage shall pass to the Customer upon delivery of the materials.In the event PWD elects to repossess any materials for which payment in full has not been made,Customer shall be responsible for any damage to or loss of materials and their component parts. Risk of Loss Although titie and ownership and the right to possession of the materials or product furnished or delivered to the Customer shall remain with PWD until the materials are fully paid for,the risk of loss for the product or materials once they are delivered to the Customer shall be the Customer's responsibility.Therefore,the customer must maintain sufficient insurance to cover any damage,vandalism or any other loss to the product or materials.Any insurance proceeds would be paid over to PWD for the full amount owed to PWD in the event of any loss. Dispute Resolution. Direct Discussion. If a dispute arises out of or relates to this Agreement,the parties shall endeavor to settle the dispute through direct discussion. Mediation. Disputes not resolved by direct discussion shall be submitted to mediation pursuant to the Construction industry Mediation Rules of the American Arbitration Association. The parties shall select the mediator within fifteen(15)days of the request for mediation. Engaging in mediation is a condition precedent to any form of binding dispute resolution. This provision shall not act to delay Supplier filing a mechanic's lien foreclosure action. The cost of any mediation proceeding shall be shared equally by the parties participating. TERMS & CONDITIONS: PLEASE READ CAREFULLY AND SIGN OR INITIAL WHERE REQUIRED.YOU ARE RESPONSIBLE FOR UNDERSTANDING THE ENCLOSED INFORMATION AS IT RELATES TO YOUR ORDER AND OUR COMPUTER PRINTOUT OF YOUR ORDER. ➢ Tax exempt# ➢ Order# ➢ Total amount of order with taxes$ your tax rate is %. ➢ A deposit of$ is required prior to factory order. ❑ TERMS OF PAYMENT Interest of one and one half percent(1-1/2%)per month will be charged on all past due accounts. If Customer or Customer's agent directs PWD to retain the products or materiafs,although availabfe for delivery,customer is responsible for payment in full within 20 days after the delivery date shown below.Customer agrees to pay all costs of collection including reasonable attorney's fees.This contract is deemed to have been entered into in the State of Colorado and Colorado law shall govern its interpretation and enforcement.Jurisdiction and venue for any legal action shall be in the County or District Court,City and County of Denver,Colorado. ❑ Delivery Your requested DELIVERY DATE is(MUST BE DELIVERED WITHIN 5 DAYS OF THIS DATE original delivery date a storage fee of$50 per week will be accessed.Please intial .When product has been in Pe�la Is aeehouse foai�u ee�han 10 days,orderl m�ust be paid in f IL ❑ DELIVERY DATES ARE NOT GUARANTEED and PWD shall not be liable for any direct,indirect or consequential damages or loss caused by delay in shipment.You will be notified as soon as possible if delivery during the above week becomes unattainable and a new delivery week will be established. Unless other arrangements are made with PWD,deliveries are tailgate and YOU MUST FURNISH LABOR TO UNLOAD. PWD assumes no responsibility or liability for injuries or damage to product after product leaves our truck. • An authorized signature is required to accept delivery. • Signed delivery tickets will be conclusive of delivery of the materials described,the quantities listed,and receipt in good and undamaged condition. • No claims for concealed damage,errors or defects in product,materials,workmanship,or shortages will be allowed unless written notice is received by PWD within three For more information regarding the finishing, maintenance, service and warranty of all PellaO products, visit the PellaO website at www.pella.com Printed on 4/22/2014 Detailed Proposal Page 3 of 5 Customer: HMR construction Project Name: HMR/All Seasons G-1B Quote Number:4684070 Line# Location: Attributes 15 S 8 H Small Zone 2-Sm Shipping � Handling$1500 or less. Thank You For Your Interest In PellaO Products Item Price Qty ExYd Price $100.00 � $100.00 PELLA WARRANTY: Pella products are covered by Pella's limited warranties in effect at the time of sale.All applicable product warranties are incorporated into and become a part of this contract. Please see the warranties for complete details,taking special note of the two important notice sections regarding installation of Pella products and proper management of moisture within the wall system.Neither Pella Corporation nor PELLA WINDOWS&DOORS,LLC will be bound by any other warranty unless specifically set out in this contract. However, Pella Corporation will not be liable for branch warranties which create obligations in addition to or obligations which are inconsistent with Pella written warranties. Clear opening(egress)information does not take into consideration the addition of a Rolscreen[or any other accessory]to the product. You should consult your local building code to ensure your Pella products meet local egress requirements. Per the manufacturer's limited warranty,unfinished mahogany exterior windows and doors must be finished upon receipt prior to installing and refinished annually,thereafter. Variations in wood grain,color,texture or natural characteristics are not covered under the limited warranty. BRANCH WARRANTY: The tull text of the manufacturer's current warranty can be found at<http://www.pella.com/products/warranry.asp>. Supplier(PWD)offers the following Limited Warranty: LIMITED WARRANTY PWD MAKES NO WARRANTIES OF MERCHANTABILITY,FITNESS FOR A PARTICULAR PURPOSE OR ANY OTHER NATURE OR GUARANTEE,EXPRESS OR IMPLIED. UPON REQUEST, PWD WILL PROVIDE THE MANUFACTURER'S WARRANTIES CURRENTLY IN EFFECT RELATED TO THE MATERIAL SUPPLIED. THE MANUFACTURER'S WARRANTIES SHALL HAVE NO EFFECT UNTIL PWD HAS BEEN PAID IN FULL ALL SUMS DUE AND OWING FOR THE PRODUCT OR MATERIALS SUPPLIED PURSUANT TO THIS CONTRACT. In no event shall PWD or Pella Corporation be liable for consequential, indirect or incidental damages or for any amount in excess of the purchase price whether the claim is for breach of warranty or negligence. NATURAL PROPERTIES OF WOOD MATERIALS Wood is a natural product and that variations in grain and shading will occur and because no hvo pieces of wood are exactly alike,variations after finishing are to be expected and are not considered defects. Custom Materials Customer recognizes and acknowledges that the product or materials supplied by PWD are custom in nature and there is no ready market or value other than for the job for which the materials For more information regarding the finishing, maintenance, service and warranty of all PellaO products, visit the Pella�website at www,pella.com Printed on 4122/2014 Detailed Proposal Page 2 of 5 �� 'Customer: HMR construction Project Name: HMR/All Seasons G-1B Q t N uo e umber.4684070 (3)working days after delivery. If concealed damage,errors or defects in product,materials,workmanship,or shortages are discovered and timely notice is received by PWD, PWD will be liable only for the reasonable costs of supplying replacement or repairs. ADDITIONS/REViSIONS/CANCELLATIONS/RETURNS All Pella Products,including windows,doors,parts and accessories are made to order and therefore non-refunable.Please review all the attributes of your order for accuracy prior to signing the purchase agreement. ❑ Any revisions after the contract date must be accompanied by a signed PWD Change Order Form,or by a separate contract. ❑ The terms of this Sales Contract shall apply to any additions,changes,and partial shipments requested for this job by the Customer or the Customer's agent. ORDER CHECKLIST-Customer must initial each I understand that I have three working days after the date of delivery to report concealed damage,errors or shortages. I or my authorized representatives have verified the product attributes,handing,color,measurements and dimensions for the product ordered. Deliveries require heavy lifting. I understand I must off load product from the truck tailgate into my home or garage. I understand that a signed and dated copy of this Sales Contract must be in the possession of Pella Windows&Doors,Inc.,along with my deposit check and credit application(if either is required), before my order can be submitted to the factory for production. I understand that all orders are subject to acceptance by an officer of PWD. I understand that the hinging and sliding designations for ALL products are as viewed from the OUTSIDE of the structure and from left to right. I understand that wood is a natural product and that variations in grain and shading will occur and because no two pieces of wood are exactly alike,variations after finishing are normal and not considered defective. I understand that building and safety code compliance is my responsibility as the purchaser. Product warranty and other important information are contained in this document. THIS DOCUMENT, INCLUDING ADDENDUMS IF APPLICABLE,AND THE TERMS AND CONDITIONS CONTAINS THE ENTIRE AGREEMENT AND BUYER REPRESENTS THAT HE HAS READ, UNDERSTANDS AND AGREES TO BE BOUND BY THE SAME. For more information regarding the finishing, maintenance, service and warranty of all PellaO products, visit the PellaO website at www.pella.com Printed on 4/22/2014 Detailed Proposal Page 4 of •Customer: HMR construction Project Name: HMR/All Seasons G-16 Quote Number•4684070 Customer Name (P�ease print) Customer Signature Date Pella Sales Rep Name (Please print) Pella Sales Rep Signature Date For more information regarding the finishing, maintenance, service and warranty of all PellaO products, visit the PellaO website at www,pella.com Printed on 4122/2014 Detailed Proposal Page 5 of 5 �