The URL can be used to link to this page

Home My WebLink AboutDRB17-0279_Pella Pricing_1499293740.pdf Proposal - Detailed Pella Window and Door Showroom of Glenwood Springs Sales Rep Name: Triebel, Michael ® 5317 Rd 154 204 Sales Rep Phone: (970) 945-2289 Glenwood Springs, CO 81601 Sales Rep E-Mail: mtriebel@pellacolorado.com Phone: (970) 945-2289 Fax: (970) 945-4419 Sales Rep Fax: (970) 945-4419 Customer Information Project/Delivery Address Order Information Aspen Grove Construction VRC/Bldg.3 Unit 3 Quote Name: 5/22/17 PO Box 817 4695 Vail Racquet Club Drive Order Number: 042 Minturn,CO 81645-0817 Lot# Quote Number: 9003752 Primary Phone: (970)471-4857 VAIL,CO 81657 Order Type: Non-Installed Sales Mobile Phone: County: EAGLE Wall Depth: Fax Number: Owner Name: Payment Terms: Deposit/C.O.D. E-Mail: Tax Code: ZZA Contact Name: Owner Phone: Cust Delivery Date: None Quoted Date: 5/22/2017 Great Plains#: 8200510 Contracted Date: Customer Number: 1008294610 Booked Date: Customer Account: 1004229102 Customer PO#: Line# Location: Attributes 10 Impervia, Sliding Window Vent Right 1 Fixed, 60 X 33, Brown Item Price Qty Ext'd Price $467.08 2 $934.16 1: Non-Standard SizeNon-Standard Size Vent Right/Fixed Double Slider r., PK# Frame Size: 60 X 33 1983 General Information: Standard, Duracast®,Nail Fin, Foam Insulated,3", 1 5/16", 1 11/16" .1:1-. Exterior Color/Finish: Brown Interior Color/Finish: Brown Glass: Insulated Low-E SunDefenseTM Low-E Insulating Glass Air Filled High Altitude Viewed From Exterior Hardware Options: Brown, No Limited Opening Hardware Rough Opening: 5'0 1/2"X 2'9 1/2" Screen: Half Screen,Conventional Fiberglass Performance Information: U-Factor 0.32,SHGC 0.22,VLT 0.49,CPD PEL-N-103-00638-00001, Performance Class LC, PG 40,Calculated Positive DP Rating 40,Calculated Negative DP Rating 40,Year Rated 08111, Egress Meets Typical for ground floor applications 5.0 sqft Grille: No Grille, Wrapping Information: No Exterior Trim, No Interior Trim,Pella Recommended Clearance,Perimeter Length= 186". Venting Width: Equal For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 1 of 8 Customer: Aspen Grove Construction Project Name: VRC/Bldg.3 Unit 3 Quote Number:9003752 Line# Location: Attributes 15 Support Product, Direct Set Fixed Frame, 27 X 60, Brown Item Price Qty Ext'd Price $506.84 1 $506.84 1:2760 Fixed Frame PK# Frame Size:27 X 60 1983 General Information: Interior Glazed,Factory Assembled, Standard,Clad, Pine,5",3 11/16" Exterior Color/Finish: Standard Enduraclad,Brown Interior Color/Finish: Unfinished Interior • 2 3 Glass: Insulated Dual Tempered Low-E SunDefenseTM Low-E Insulating Glass Air Filled High Altitude Viewed From Exterior Performance Information: U-Factor 0.32,SHGC 0.24,VLT 0.57,CPD PEL-N-18-02771-00001, Performance Class CW, PG 90,Calculated Positive DP Rough Opening: 2'3 3/4"X 5'0 3/4" Rating 90,Calculated Negative DP Rating 90,Year Rated 08111 Grille: No Grille, Wrapping Information: Foldout Fins, Factory Applied,No Exterior Trim, No Interior Trim,6 11/16",8",Standard Four Sided Jamb Extension,Factory Applied, Pella Recommended Clearance, Perimeter Length=174". Line# Location: Attributes 20 Designer, Double Sliding Door, Contemporary, Vent Right I Fixed, 71.25 X 81.5, Brown Item Price Qty Ext'd Price $3,394.99 1 $3,394.99 1:7282 Vent Right/Fixed Double Sliding Door PK# Frame Size: 71 1/4 X 81 1/2 1983 General Information: Clad,5 7/8",4 9/16",Oak Threshold Exterior Color/Finish: Standard Enduraclad,Brown Interior Color/Finish: Unfinished Interior S 11 114 — Glass: Insulated Tempered Low-E SunDefenseTM Low-E Insulating Glass Air Filled High Altitude Viewed From Exterior Hinge Panel: Clear,Tempered Rough Opening: 6'0"X 6'10" Hardware Options: Black, Plazo, Handle Included, Handle Included,Satin Nickel,Satin Nickel, No Integrated Sensor Screen:Sliding Screen,Wood Interior Color Matched Exterior,Satin Nickel, InViewTM Unit Accessories:Snap-In Between-The-Glass Fabric Shade Bottom-Up, Linen, Manual Performance Information: U-Factor 0.29,SHGC 0.19,VLT 0.42,CPD PEL-N-231-00006-00001, Performance Class LC, PG 40,Calculated Positive DP Rating 40,Calculated Negative DP Rating 40,Year Rated 08111 Grille: No Grille, Wrapping Information: Foldout Fins, Factory Applied,No Exterior Trim,No Interior Trim,6 11/16",8",Factory Applied, Pella Recommended Clearance, Perimeter Length=306". For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 2 of 8 Customer: Aspen Grove Construction Project Name: VRC/Bldg.3 Unit 3 Quote Number:9003752 Line# Location: Attributes 25 Designer, Inswing Door Left, 37.875 X 81.5, Brown Item Price Qty Ext'd Price $2,390.48 1 $2,390.48 1:3882 Left Inswing Door PK# Frame Size:37 7/8 X 81 1/2 co I 1983 General Information: Standard,Clad,8",6 11/16",Standard Sill, Brown Finish Sill Exterior Color/Finish: Standard Enduraclad,Brown Interior Color/Finish: Unfinished Interior '3 170 ' Glass: Insulated Tempered Low-E SunDefenseTM Low-E Insulating Glass Air Filled High Altitude Viewed From Exterior Hinge Panel: Clear,Tempered Rough Opening: 3'2 5/8"X 6'10" Hardware Options:Spiere,Satin Nickel,Order Handle Set,Multipoint Lock,No Integrated Sensor Screen: No Screen Unit Accessories:Snap-In Between-The-Glass Fabric Shade Bottom-Up, Linen, Manual Performance Information: U-Factor 0.27,SHGC 0.14,VLT 0.31,CPD PEL-N-3-02062-00001, Performance Class LC, PG 55,Calculated Positive DP Rating 55,Calculated Negative DP Rating 70,Year Rated 08111 Grille: No Grille, Wrapping Information: Foldout Fins, Factory Applied,No Exterior Trim,No Interior Trim,6 11/16",8",Factory Applied, Pella Recommended Clearance, Perimeter Length=239". Line# Location: Attributes 30 S & H Tailgate Zone 2- Std Shipping & Handling non-taxable Z2 Item Price Qty Ext'd Price $330.00 1 $330.00 Thank You For Your Interest In Pella® Products For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 3 of 8 Customer:Aspen Grove Construction Project Name: VRC/Bldg. 3 Unit 3 Quote Number: 9003752 PELLA WARRANTY: Pella products are covered by Pella's limited warranties in effect at the time of sale.All applicable product warranties are incorporated into and become a part of this contract. Please see the warranties for complete details,taking special note of the two important notice sections regarding installation of Pella products and proper management of moisture within the wall system.Neither Pella Corporation nor PELLA WINDOWS&DOORS,LLC will be bound by any other warranty unless specifically set out in this contract. However,Pella Corporation will not be liable for branch warranties which create obligations in addition to or obligations which are inconsistent with Pella written warranties. Clear opening(egress)information does not take into consideration the addition of a Rolscreen[or any other accessory]to the product.You should consult your local building code to ensure your Pella products meet local egress requirements. Per the manufacturer's limited warranty,unfinished mahogany exterior windows and doors must be finished upon receipt prior to installing and refinished annually,thereafter. Variations in wood grain,color,texture or natural characteristics are not covered under the limited warranty. INSYNCTIVE PRODUCTS:In addition,Pella Insynctive Products are covered by the Pella Insynctive Products Software License Agreement and Pella Insynctive Products Privacy Policy in effect at the time of sale,which can be found at Insynctive.pella.com. By installing or using Your Insynctive Products you are acknowledging the Insynctive Software Agreement and Privacy Policy are part of the terms of sale. ARBITRATION AND CLASS ACTION WAIVER("ARBITRATION AGREEMENT") YOU and Pella and its subsidiaries and the Pella Branded Distributor AGREE TO ARBITRATE DISPUTES ARISING OUT OF OR RELATING TO YOUR PELLA PRODUCTS(INCLUDES PELLA GOODS AND PELLA SERVICES)AND WAIVE THE RIGHT TO HAVE A COURT OR JURY DECIDE DISPUTES.YOU WAIVE ALL RIGHTS TO PROCEED AS A MEMBER OR REPRESENTATIVE OF A CLASS ACTION,INCLUDING CLASS ARBITRATION,REGARDING DISPUTES ARISING OUT OF OR RELATING TO YOUR PELLA PRODUCTS.You may opt out of this Arbitration Agreement by providing notice to Pella no later than ninety(90)calendar days from the date You purchased or otherwise took ownership of Your Pella Goods.To opt out,You must send notice by e-mail to pellawebsupportApella.c om,with the subject line: "Arbitration Opt Out"or by calling(877)473-5527.Opting out of the Arbitration Agreement will not affect the coverage provided by any applicable limited warranty pertaining to Your Pella Products.For complete information,including the full terms and conditions of this Arbitration Agreement,which are incorporated herein by reference,please visit www.pella.com/arbitration or e-mail to pellawebsupport@pella.com,with the subject line:"Arbitration Details"or call(877)473-5527. D'ARBITRAGE ET RENONCIATION AU RECOURS COLLECTIF("convention d'arbitrage")EN FRAKAIS SEE PELLA.COM/ARBITRATION. DE ARBITRAJE Y RENUNCIA COLECTIVA("acuerdo de arbitraje")EN ESPANOL VER PELLA.COM/ARBITRATION. Product Performance Information: U-Factor, Solar Heat Gain Coefficient(SHGC),and Visible Light Transmittance(VLT)are certified by the National Fenestration Rating Council(NFRC).Manufacturer stipulates that these ratings conform to applicable NFRC procedures for determining whole product performance.NFRC ratings are determined for a fixed set of environmental conditions and a specific product size.NFRC does not recommend any products and does not warrant the suitability of any product for any specific use. Design Pressure(DP),Performance Class,and Performance Grade(PG)are certified by a third party organization,in many cases the Window and Door Manufacturers Association (WDMA). The certification requires the performance of at least one product of the product line to be tested in accordance with the applicable performance standards and verified by an independent party. The certification indicates that the product(s)of the product line passed the applicable tests. The certification does not apply to mulled and/or product combinations unless noted.Actual product results will vary and change over the products life. For more performance information along with information on Florida Product Approval System(FPAS)Number and Texas Dept.of Insurance(TDI)number go to www.pella.com /performance. BRANCH WARRANTY: For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 4 of 8 Customer: Aspen Grove Construction Project Name: VRC/Bldg.3 Unit 3 Quote Number:9003752 The full text of the manufacturer's current warranty can be found at<http://www.pella.com/products/warranty.asp>. Supplier(PWD)offers the following Limited Warranty: LIMITED WARRANTY THE PELLA LIMITED WARRANTY EXCLUDES NON-PELLA PRODUCTS FROM WARRANTY COVERAGE STATED IN THIS DOCUMENT. SEE YOUR SALES REPRESENTATIVE FOR SPECIFIC PRODUCT WARRANTY INFORMATION.ALL NON-PELLA PRODUCTS CARRY A 1 YEAR LIMITED WARRANTY. NOTE*-NO WARRANTY IS PROVIDED FOR CONSEQUENTIAL DAMAGES. PWD MAKES NO WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE OR ANY OTHER NATURE OR GUARANTEE, EXPRESS OR IMPLIED. UPON REQUEST, PWD WILL PROVIDE THE MANUFACTURER'S WARRANTIES CURRENTLY IN EFFECT RELATED TO THE MATERIAL SUPPLIED. THE MANUFACTURER'S WARRANTIES SHALL HAVE NO EFFECT UNTIL PWD HAS BEEN PAID IN FULL ALL SUMS DUE AND OWING FOR THE PRODUCT OR MATERIALS SUPPLIED PURSUANT TO THIS CONTRACT. In no event shall PWD or Pella Corporation be liable for consequential,indirect or incidental damages or for any amount in excess of the purchase price whether the claim is for breach of warranty or negligence. NATURAL PROPERTIES OF WOOD MATERIALS Wood is a natural product and that variations in grain and shading will occur and because no two pieces of wood are exactly alike,variations after finishing are to be expected and are not considered defects. Custom Materials Customer recognizes and acknowledges that the product or materials supplied by PWD are custom in nature and there is no ready market or value other than for the job for which the materials are manufactured and/or supplied. If Customer at any time fails to pay PWD for the materials supplied, PWD may,at it's option,suspend all deliveries or terminate the Contract with the Customer.Such suspension or termination DOES NOT excuse payment for those materials and products already manufactured at the full contract price or payment for any component parts already purchased and obtained by PWD. Title Title,ownership and the right to possession of the product or materials furnished or to be furnished by PWD shall remain in PWD until PWD is paid in full. PWD shall have a right to possession of the product or materials but is not obligated to repossess the materials in the event of non-payment. PWD's right to repossess materials is in addition to,and not a limitation upon or a waiver of PWD's other legal rights including the right to place mechanic's liens against the real property for which materials were supplied.All risk of loss or damage shall pass to the Customer upon delivery of the materials. In the event PWD elects to repossess any materials for which payment in full has not been made,Customer shall be responsible for any damage to or loss of materials and their component parts. Risk of Loss Although title and ownership and the right to possession of the materials or product furnished or delivered to the Customer shall remain with PWD until the materials are fully paid for,the risk of loss for the product or materials once they are delivered to the Customer shall be the Customer's responsibility.Therefore,the customer must maintain sufficient insurance to cover any damage,vandalism or any other loss to the product or materials.Any insurance proceeds would be paid over to PWD for the full amount owed to PWD in the event of any loss. Dispute Resolution. Direct Discussion. If a dispute arises out of or relates to this Agreement,the parties shall endeavor to settle the dispute through direct discussion. Mediation. Disputes not resolved by direct discussion shall be submitted to mediation pursuant to the Construction Industry Mediation Rules of the American Arbitration Association. The parties shall select the mediator within fifteen(15)days of the request for mediation. Engaging in mediation is a condition precedent to any form of binding dispute resolution. This provision shall not act to delay Supplier filing a mechanic's lien foreclosure action. The cost of any mediation proceeding shall be shared equally by the parties participating. TERMS &CONDITIONS: PLEASE READ CAREFULLY AND SIGN OR INITIAL WHERE REQUIRED.YOU ARE RESPONSIBLE FOR UNDERSTANDING THE ENCLOSED INFORMATION AS IT RELATES TO YOUR ORDER AND OUR COMPUTER PRINTOUT OF YOUR ORDER. ➢ Tax exempt# For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 5 of 8 Customer: Aspen Grove Construction Project Name: VRC/Bldg.3 Unit 3 Quote Number:9003752 ➢ Order# PO# ➢ Total amount of order with taxes$ your tax rate is %. ➢ A deposit of$ is required prior to factory order. ❑ TERMS OF PAYMENT Interest of one and one half percent(1-1/2%)per month will be charged on all past due accounts. If Customer or Customer's agent directs PWD to retain the products or materials,although available for delivery,customer is responsible for payment in full within 20 days after the delivery date shown below.Customer agrees to pay all costs of collection including reasonable attorney's fees.This contract is deemed to have been entered into in the State of Colorado and Colorado law shall govern its interpretation and enforcement.Jurisdiction and venue for any legal action shall be in the County or District Court,City and County of Denver,Colorado. ❑ Delivery Your requested DELIVERY DATE is(MUST BE DELIVERED WITHIN 5 DAYS OF THIS DATE) . In the event of failure to receive product within 10 days of your original delivery date a storage fee of$50 per week will be accessed. Please intial .When product has been in Pella's warehouse for more than 10 days,order must be paid in full. ❑ DELIVERY DATES ARE NOT GUARANTEED and PWD shall not be liable for any direct, indirect or consequential damages or loss caused by delay in shipment.You will be notified as soon as possible if delivery during the above week becomes unattainable and a new delivery week will be established. Unless other arrangements are made with PWD,deliveries are tailgate and YOU MUST FURNISH LABOR TO UNLOAD. PWD assumes no responsibility or liability for injuries or damage to product after product leaves our truck. • An authorized signature is required to accept delivery. • Signed delivery tickets will be conclusive of delivery of the materials described,the quantities listed,and receipt in good and undamaged condition. • No claims for concealed damage,errors or defects in product, materials,workmanship,or shortages will be allowed unless written notice is received by PWD within three (3)working days after delivery. If concealed damage,errors or defects in product, materials,workmanship,or shortages are discovered and timely notice is received by PWD, PWD will be liable only for the reasonable costs of supplying replacement or repairs. ADDITIONS/REVISIONS/CANCELLATIONS/RETURNS All Pella Products, including windows,doors,parts and accessories are made to order and therefore non-refunable. Please review all the attributes of your order for accuracy prior to signing the purchase agreement. ❑ Any revisions after the contract date must be accompanied by a signed PWD Change Order Form, or by a separate contract. ❑ The terms of this Sales Contract shall apply to any additions,changes,and partial shipments requested for this job by the Customer or the Customer's agent. ORDER CHECKLIST-CUSTOMER MUST INITIAL EACH I understand that I have three working days after the date of delivery to report concealed damage,errors or shortages. I or my authorized representatives have verified the product attributes, handing,color, measurements and dimensions for the product ordered. Deliveries require heavy lifting. I understand I must off load product from the truck tailgate into my home or garage. I understand that a signed and dated copy of this Sales Contract must be in the possession of Pella Windows& Doors, Inc.,along with my deposit check and credit application(if either is required),before my order can be submitted to the factory for production. I understand that all orders are subject to acceptance by an officer of PWD. I understand that the hinging and sliding designations for ALL products are as viewed from the OUTSIDE of the structure and from left to right. I understand that wood is a natural product and that variations in grain and shading will occur and because no two pieces of wood are exactly alike,variations after finishing are normal and not considered defective. I understand that building and safety code compliance is my responsibility as the purchaser. Product warranty and other important information are contained in this document. For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 6 of 8 Customer: Aspen Grove Construction Project Name: VRC/Bldg.3 Unit 3 Quote Number:9003752 THIS DOCUMENT, INCLUDING ADDENDUMS IF APPLICABLE,AND THE TERMS AND CONDITIONS CONTAINS THE ENTIRE AGREEMENT AND BUYER REPRESENTS THAT HE HAS READ, UNDERSTANDS AND AGREES TO BE BOUND BY THE SAME. SERVICE: Please sign the very last page and return to Pella as your acceptance of this quote. Parts take up to two weeks to arrive and must be paid in full at time of order however; labor can be paid up on completion of the job. Quotes are valid for 60 days and subject to rebid after such time. Please contact Customer Service with any questions you may have at 800-423-7511. For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 7 of 8 Customer: Aspen Grove Construction Project Name: VRC/Bldg.3 Unit 3 Quote Number:9003752 Customer Name (Please print) Pella Sales Rep Name (Please print) Order Totals Taxable Subtotal $7,226.47 Sales Tax @ 2.9% $209.57 Customer Signature Pella Sales Rep Signature Non-taxable Subtotal $330.00 Date Date Total $7,766.04 Deposit Received Amount Due $7,766.04 For more information regarding the finishing, maintenance, service and warranty of all Pella®products, visit the Pella®website at www.pella.com Printed on 5/22/2017 Detailed Proposal Page 8 of 8