Loading...
HomeMy WebLinkAboutB17-0405_Roofing Contract_1507657680.pdfSubmitted to: Alex Garcia 2418 W. Garmich Dr. Vail, Co. 81657 970-376-7544 PRIME ROOFING CONTRACT Z & Z Roofing LLC Sergio Gonzalez 08/10/2017 10/10/17 Owner/Buyer Authorized Signature DateContractor/Seller Signature Date THIS CONTRACT IS ENTERED INTO THIS DATE: OWNER/BUYER NAME OWNER’S ADDRESS OWNER’S HOME PHONE OWNER’S WORK PHONE PROJECT ADDRESS PROJECT PHONE PROJECT PHONE 2 WE HEREBY PROPOSE to furnish all materials and necessary equipment, and perform all labor necessary to complete the following work (Describe Labor, Material and Equipment to be furnished): Contractor/Seller Signature Date OWNER'S CITY, STATE & POSTAL CODE PROJECT NAME PROJECT CITY, STATE & POSTAL CODE CONSTRUCTION LENDER IS: (Name and address of construction fund holder) (Name and Branch Address of Bank, Saving and Loan Assn., Escrow Agent, Joint Control or Other) TIME FOR COMPLETION: The work to be performed by Contractor pursuant to this Agreement shall be substantially completed within ( ) days or approximately on . INTEREST: Overdue payments will bear interest at the rate of 1½ % per month. PAYMENT: This is a cash transaction. Owner agrees to pay Contractor a total cash price of: . Dollars Down payment (if any) $ with payments to be made as follows: Alex Garcia Vail, Co. 81657 Reroof City. State and zip code or same as Owner’s 2418 W. Garmich Dr. 08/10/2017 970-376-7544 Project /job address or same as Owner’s Address Please see sheets attached whit complete description. 0 $ see sheets attached 65% Deposit or early billing for material will be required. PRIME ROOFING CONTRACTZ & Z Roofing LLC P.O 10/10/17 SCOPE OF WORK. ➢ Will provide labor and material. ➢ All flashing will be of the color selected by the owner. ➢ Remove the gravel and save. ➢ Remove existing torch down (2,000 square ft. approximate). ➢ Replace 55’of Fascia. ➢ Install 1 layers of Plywood 100%. ➢ Install fiber glass base. ➢ Fabricate and Install 55’ of metal flashing drip edge with gravel stop. ➢ Fabricate and Install 70’ of metal flashing rake with gravel stop. ➢ Install 2,000 square ft. of torch down. ➢ Reinstall the gravel. ➢ Replace all the pipe Flashing. Estimate cost. ---------------------------------------------------------------------------$ 21,400.00 Specifications. ➢ If there is damage in the rafters or something else that must repair or replace will be charged as time and material. ➢ This price includes manufacture, delivery, installation, tear off and Dump trash. ➢ Permit provided by the owner. ➢ All material is guaranteed to be as specified. ➢ One year of warranty in labor. ➢ Early billing for materials will be required (65%). ➢ Insurance Is fully insured with liability insurance in the amount of $2,000,000 and all workers are fully covered by Workman’s Compensation Insurance. ➢ Please be advised that materials for this proposal have been bid at current market prices and cannot be guaranteed past 30 days. Options. The price will change when you choose one of the options. ➢ Fabricate and provide all type of flashing transition flashings for windows, doors, belly bends, stone, post caps and siding. ➢ Fabricate and install seamless and half round gutters. ➢ Fabricate and install chimney caps and post caps. ➢ Install snow clips or snow fences and Heat tape. 10/10/17 TERMS AND CONDITIONS I. CHANGES IN THE WORK. Should the owner, construction lender, or any public body or inspector direct any modification or addition to the work covered by this contract, the contract price shall be adjusted accordingly. Modification or addition to the work shall be executed only when both the Owner and the Contractor have signed a contract Change Order. The change in the contract price caused by such contract Change Order shall be as agreed to in writing, or if the parties are not in agreement as to the change in contract price, the Contractor’s actual cost of all labor, equipment, subcontracts and materials, plus a Contractor’s fee of 15 % shall be the change in contract price. The Change Order may also increase the time within which the contract is to be completed. Contractor shall promptly notify the Owner of (a) latent physical conditions at the site differing materially from those indicated in the contract, or (b) unknown physical conditions differing materially from those ordinarily encountered and generally recognized as inherent in work of the character provided for in this contract. Owner as added work shall pay for any expenses incurred due to such conditions. II. OWNER’S RESPONSIBILITIES. Owner agrees to allow and provide Contractor and equipment access to the property. III. DELAYS. Contractor agrees to start and diligently pursue work through to completion, but shall not be responsible for delays for any of the following reasons: failure of the issuance of all necessary building permits within a reasonable length of time, funding of loans, disbursement of funds into funding control or escrow, acts of neglect or omission of Owner or Owner’s employees or Owner’s agent, acts of God, stormy or inclement weather, strikes, lockouts, boycotts, or other labor union activities, extra work ordered by Owner, acts of public enemy, riots or civil commotion, inability to secure material through regular recognized channels, imposition of Government priority or allocation of materials, failure of Owner to make payments when due, or delays caused by inspection or changes ordered by the inspectors of authorized governmental bodies, or for acts of independent contractors, or holidays, or other causes beyond Contractor’s reasonable control. IV. SUBCONTRACTS. The Contractor may subcontract portions of this work to properly licensed and qualified subcontractors. V. TAXES AND ASSESMENTS. Owner will pay for taxes and assessments of all descriptions. VI. INSURANCE AND DEPOSITS. Contractor shall carry Worker’s Compensation Insurance for the protection of Contractor’s employees during the progress of the work. Contractor shall carry liability insurance to cover any damages to Owner’s property resulting out of the acts of Contractor. Owner shall obtain and pay for insurance against injury to his own employees and persons under persons on the job site at Owner’s invitation. Owner shall also procure at own expense and before the commencement of work hereunder “all-risk” insurance with course of construction, theft, vandalism and malicious mischief endorsements attached, the insurance to be in a sum at least equal to the contract price. The insurance shall name the Contractor and any subcontractors as additional insured’s, and will be written to protect owner, Contractor and subcontractors as their interests may appear. Should Owner fail to procure such insurance, Contractor may do so at the expense of Owner, but is not required to do so. Owner and Contractor waive rights of subrogation against each other to the extent that any loss is covered by valid and collectible insurance. If the project is destroyed or damaged by accident, disaster, or calamity such as fire, storm, flood, landslide, subsidence or earthquake, owner as extra work shall pay for work done by Contractor in rebuilding or restoring the project. VII. RIGHT TO STOP WORK. Contractor shall have the right to stop work if any payment shall not be made, when due, to Contractor under this Agreement; Contractor may keep the job idle until all payments due are received. Failure to make payment, within five (5) days of the due date, is a material breach of this Agreement and shall entitle contractor to cease any further work. VIII. CLEAN UP. Contractor will remove from Owner’s property debris and surplus material created by the operation and leave it in a neat and broom clean condition. IX. COMPLIANCE WITH LAWS. In connection with the performance by Contractor of duties pursuant to this Agreement, Contractor shall obtain and pay for all permits and comply with all federal, state, county and local laws, ordinances and regulations. X. ARBITRATION, VALIDITY AND DAMAGES. Any controversy or claim arising out of or related to this contract, or the breach thereof, shall be settled by arbitration in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association, and judgment upon the award rendered by the Arbitrator(s) may be entered in any court having jurisdiction thereof. XI. ASBESTOS AND HAZARDOUS WASTE. Unless the contract specifically calls for the removal, disturbance, or transportation of asbestos or other hazardous substances, the parties acknowledge that such work requires special procedures, precautions, and/or licenses. Therefore, unless the contract specifically calls for same, if Contractor encounters such substances, Contractor shall immediately stop work and allow the Owner to obtain a duly qualified asbestos and/or hazardous material contractor to perform the work or do the work at contractor’s option. Said work shall be treated as an extra under the contract. XII. ATTORNEY FEES. In the event legal action or arbitration instituted for the enforcement of any term or condition of this contract, the prevailing party shall be entitled to an award of reasonable attorney’s fees in said action or arbitration, in addition to costs and reasonable expenses incurred in the prosecution or defense of said action or arbitration. © 1992-2008 SnappyFORMS.com Form #00451 Roofing Prime Contract 10/10/17