Loading...
HomeMy WebLinkAboutB17-0405_Roofing Contract.pdf 10OF Iv Submitted to: Alex Garcia J ��� ,, Oil 2418 W. Garmich Dr. 10/10/17 0111 Vail, Co. 81657 IIII 970-376-7544 IIII PRIME ROOFING CONTRACT Z & Z Roofing LLC Sergio Gonzalez 08/10/2017 PI it z & z-..... 1..0 Box 1154 ROOFING CON Eagle,CO,81631 ' ' Roofing LLC (970)470_0256 +ii ktk Sergio@z and.roofing.com 7 www.zandzroofing.com ' 1q0 THIS CONTRACT IS ENTERED INTO THIS DATE: 1 Vll Vll/ 08/10/2017 OWNER/BUYER NAME OWNER'S ADDRESS Alex Garcia 2418 W. Garmich Dr. OWNER'S CITY,STATE&POSTAL CODE OWNER'S HOME PHONE OWNER'S WORK PHONE Vail, Co. 81657 970-376-7544 PROJECT NAME PROJECT ADDRESS Reroof Project /job address or same as Owner's Address PROJECT CITY,STATE&POSTAL CODE PROJECT PHO E PROJECT PHONE 2 City. State and zip code or same as Owner's CONS RUCTION LENDER IS:(Name and address of construction fund holder) (Name and Branch Address of Bank,Saving and Loan Assn.,Escrow Agent,Joint Control or Other) WE HEREBY PROPOSE to furnish all materials and necessary equipment, and perform all labor necessary to complete the following work (Describe Labor, Material and Equipment to be furnished): Please see sheets attached whit complete description. TIME FOR COMPLETION:The work to be performed by Contractor pursuant to this Agreement shall be substantially completed within ( 0 )days or approximately on INTEREST: Overdue payments will bear interest at the rate of 1'/2% per month. PAYMENT: This is a cash transaction. Owner agrees to pay Contractor a total cash price of: $ see sheets attached . Dollars Down payment (if any)$ 65% with payments to be made as follows: Deposit or early billing for material will be required. Contractor/Seller Signature Date Contractor/Seller Signature Date Owner/Buyer Authorized Signature Dale i 'In c !EC 47r SCOPE OF WORK. opo ➢ Will provide labor and material. 10/10/17 ➢ All flashing will be of the color selected by the owner. ➢ Remove the gravel and save. ➢ Remove existing torch down (2,000 square ft. approximate). ➢ Replace 55'of Fascia. ➢ Install 1 layers of Plywood 100%. ➢ Install fiber glass base. ➢ Fabricate and Install 55' of metal flashing drip edge with gravel stop. ➢ Fabricate and Install 70' of metal flashing rake with gravel stop. ➢ Install 2,000 square ft. of torch down. ➢ Reinstall the gravel. ➢ Replace all the pipe Flashing. Estimate cost. $ 21,400.00 Specifications. ➢ If there is damage in the rafters or something else that must repair or replace will be charged as time and material. ➢ This price includes manufacture, delivery, installation, tear off and Dump trash. ➢ Permit provided by the owner. ➢ All material is guaranteed to be as specified. ➢ One year of warranty in labor. ➢ Early billing for materials will be required (65%). ➢ Insurance Is fully insured with liability insurance in the amount of $2,000,000 and all workers are fully covered by Workman's Compensation Insurance. ➢ Please be advised that materials for this proposal have been bid at current market prices and cannot be guaranteed past 30 days. Options. The price will change when you choose one of the options. ➢ Fabricate and provide all type of flashing transition flashings for windows, doors, belly bends, stone, post caps and siding. ➢ Fabricate and install seamless and half round gutters. ➢ Fabricate and install chimney caps and post caps. ➢ Install snow clips or snow fences and Heat tape. " Off �r TERMS AND CONDITIONS aaft r7r c I. CHANGES IN THE WORK. Should the owner, construction of construction, theft, vandalism and mal ilk eh. lender, or any public body or inspector direct any modification endorsements attached, the insurance to be in mbj or addition to the work covered by this contract, the contract equal to the contract price. The insurance sha -leD — price shall be adjusted accordingly. Modification or addition to Contractor and any subcontractors as additional insure• , . • the work shall be executed only when both the Owner and the will be written to protect owner, Contractor andis°u?contractors Contractor have signed a contract Change Order. The change as their interests may appear. Should Owner fail to procure in the contract price caused by such contract Change Order such insurance, Contractor may do so at the expense of shall be as agreed to in writing, or if the parties are not in Owner, but is not required to do so. Owner and Contractor agreement as to the change in contract price, the Contractor's waive rights of subrogation against each other to the extent that actual cost of all labor, equipment, subcontracts and materials, any loss is covered by valid and collectible insurance. If the plus a Contractor's fee of 15% shall be the change in contract project is destroyed or damaged by accident, disaster, or price. The Change Order may also increase the time within calamity such as fire, storm, flood, landslide, subsidence or which the contract is to be completed. Contractor shall promptly earthquake, owner as extra work shall pay for work done by notify the Owner of (a) latent physical conditions at the site Contractor in rebuilding or restoring the project. differing materially from those indicated in the contract, or (b) unknown physical conditions differing materially from those VII. RIGHT TO STOP WORK. Contractor shall have the right ordinarily encountered and generally recognized as inherent in to stop work if any payment shall not be made, when due, to work of the character provided for in this contract. Owner as Contractor under this Agreement; Contractor may keep the job added work shall pay for any expenses incurred due to such idle until all payments due are received. Failure to make conditions. payment, within five (5) days of the due date, is a material breach of this Agreement and shall entitle contractor to cease II.OWNER'S RESPONSIBILITIES.Owner agrees to allow and any further work. provide Contractor and equipment access to the property. VIII. CLEAN UP.Contractor will remove from Owner's property III. DELAYS. Contractor agrees to start and diligently pursue debris and surplus material created by the operation and leave work through to completion, but shall not be responsible for it in a neat and broom clean condition. delays for any of the following reasons: failure of the issuance of all necessary building permits within a reasonable length of IX. COMPLIANCE WITH LAWS. In connection with the time, funding of loans, disbursement of funds into funding performance by Contractor of duties pursuant to this control or escrow, acts of neglect or omission of Owner or Agreement, Contractor shall obtain and pay for all permits and Owner's employees or Owner's agent, acts of God, stormy or comply with all federal, state, county and local laws, ordinances inclement weather, strikes, lockouts, boycotts, or other labor and regulations. union activities, extra work ordered by Owner, acts of public enemy, riots or civil commotion, inability to secure material X. ARBITRATION, VALIDITY AND DAMAGES. Any through regular recognized channels, imposition of controversy or claim arising out of or related to this contract, or Government priority or allocation of materials, failure of Owner the breach thereof, shall be settled by arbitration in accordance to make payments when due, or delays caused by inspection with the Construction Industry Arbitration Rules of the or changes ordered by the inspectors of authorized American Arbitration Association, and judgment upon the governmental bodies, or for acts of independent contractors, or award rendered by the Arbitrator(s) may be entered in any holidays, or other causes beyond Contractor's reasonable court having jurisdiction thereof. control. XI. ASBESTOS AND HAZARDOUS WASTE. Unless the IV. SUBCONTRACTS. The Contractor may subcontract contract specifically calls for the removal, disturbance, or portions of this work to properly licensed and qualified transportation of asbestos or other hazardous substances, the subcontractors. parties acknowledge that such work requires special procedures, precautions, and/or licenses. Therefore, unless V. TAXES AND ASSESMENTS. Owner will pay for taxes and the contract specifically calls for same, if Contractor encounters assessments of all descriptions. such substances, Contractor shall immediately stop work and allow the Owner to obtain a duly qualified asbestos and/or VI. INSURANCE AND DEPOSITS. Contractor shall carry hazardous material contractor to perform the work or do the Worker's Compensation Insurance for the protection of work at contractor's option. Said work shall be treated as an Contractor's employees during the progress of the work. extra under the contract. Contractor shall carry liability insurance to cover any damages to Owner's property resulting out of the acts of Contractor. XII. ATTORNEY FEES. In the event legal action or arbitration Owner shall obtain and pay for insurance against injury to his instituted for the enforcement of any term or condition of this own employees and persons under persons on the job site at contract, the prevailing party shall be entitled to an award of Owner's invitation. Owner shall also procure at own expense reasonable attorney's fees in said action or arbitration, in and before the commencement of work hereunder "all-risk" addition to costs and reasonable expenses incurred in the insurance with course prosecution or defense of said action or arbitration. ©1992-2008 SnappyFORMS.com Form#00451 Roofing Prime Contract